The Shoreside Power Supply is to supply Oceankaj and Langeliniekaj, two quays situated in the port of Copenhagen, with the converter situated at Oceankaj.
The project includes the complete design, deliverance and execution of a converter station incl. isolations transformers, shoreside power distribution, cable management systems (Shoreside Power System, SPS) incl. any necessary connection boxes, which will connect with a shore power supply for cruise ships calling at both Oceankaj in Nordhavn and Langeliniekaj in Copenhagen Inner Harbour.
The Supplier shall as a turnkey Supplier be responsible for and perform the complete design, including Design management and ICT management, and execute all turnkey supply services.
Deadline
Fristen for modtagelse af bud var på 2023-08-04.
Indkøbet blev offentliggjort på 2023-05-26.
Objekt Omfanget af udbuddet
Titel:
“CPH City & Port I/S’ (Udviklingsselskabet By & Havn I/S’) public procurement procedure concerning Shoreside Power Supply 2023”
Produkter/tjenester: Elektriske maskiner, apparatur, udstyr og forbrugsartikler; belysning📦
Kort beskrivelse:
“The Shoreside Power Supply is to supply Oceankaj and Langeliniekaj, two quays situated in the port of Copenhagen, with the converter situated at...”
Kort beskrivelse
The Shoreside Power Supply is to supply Oceankaj and Langeliniekaj, two quays situated in the port of Copenhagen, with the converter situated at Oceankaj.
The project includes the complete design, deliverance and execution of a converter station incl. isolations transformers, shoreside power distribution, cable management systems (Shoreside Power System, SPS) incl. any necessary connection boxes, which will connect with a shore power supply for cruise ships calling at both Oceankaj in Nordhavn and Langeliniekaj in Copenhagen Inner Harbour.
The Supplier shall as a turnkey Supplier be responsible for and perform the complete design, including Design management and ICT management, and execute all turnkey supply services.
Vis mere
Anslået værdi uden moms: DKK 140 000 000 💰
1️⃣
Yderligere produkter/tjenester: Transformatorer📦
Yderligere produkter/tjenester: Strømforsyningstransformatorer📦
Yderligere produkter/tjenester: Stærkstrømskabler📦
Yderligere produkter/tjenester: Kabeltilbehør, isoleret📦
Yderligere produkter/tjenester: Ingeniørmæssig projektering📦
Sted for udførelsen: Byen København🏙️
Beskrivelse af udbuddet:
“CPH City & Port I/S’ (in the following referred to as “the Contracting Authority”) has initiated this tender procedure concerning Shoreside Power Supply,...”
Beskrivelse af udbuddet
CPH City & Port I/S’ (in the following referred to as “the Contracting Authority”) has initiated this tender procedure concerning Shoreside Power Supply, SPS. The Shoreside Power Supply is to supply Oceankaj and Langeliniekaj, two quays situated in the port of Copenhagen, with the converter situated at Oceankaj. The project includes the complete design, deliverance and execution of a converter station incl. isolations transformers, shoreside power distribution, cable management systems (Shoreside Power System, SPS) incl. any necessary connection boxes, which will connect with a shore power supply for cruise ships calling at both Oceankaj in Nordhavn and Langeliniekaj in Copenhagen Inner Harbour.
The Supplier shall as a turnkey Supplier be responsible for and perform the complete design, including Design management and ICT management, and execute all turnkey supply services (hereinafter referred to as the “Services”).
The Design and Supply Contract has the following options (“Options”), cf. section 6 of the Design and Supply Contract.
• Option 1: Additional frequency converter capacity needed to reach a total capacity of at least 48 MVA measured as a sum at the ship connection plugs. The added frequency converters and their auxiliary equipment shall have same specifications as the equipment supplied in the basic scope.
• Option 2: One additional mobile cable system crane, rated to 16 MVA, available at Oceankaj with possibility to connect to any of the shore side terminal boxes O-T1, O-T2, O-T3. The additional mobile cable system crane vehicles shall have same specifications as the equipment supplied in the basic scope.
• Option 3: The Service & Maintenance Agreement has a duration of 2 years with an option to increase with a duration of 1 year for three times, i.e. af total duration for up to 5 years.
• Option 4: Additional earthing switch housing and required cabling from earthing switch housing and to CMS and CMS solution at Langelinie at a capacity of 16 MVA.
The Contract will be carried out in the period 5 September 2023 – 6 March 2025 with subsequent Stability Test, service & maintenance, one-year inspection etc.
Vis mere Kriterier for tildeling
Kvalitetskriterium (navn): Technical solution
Kvalitetskriterium (vægtning): 25 %
Kvalitetskriterium (navn): Organisation and staffing
Kvalitetskriterium (vægtning): 10 %
Kvalitetskriterium (navn): Process description
Pris (justeringskoefficient): 55 %
Omfanget af udbuddet
Anslået samlet værdi ekskl. moms: DKK 140 000 000 💰
Varighed
Startdato: 2023-09-05 📅
Slutdato: 2025-03-06 📅
Oplysninger om valgmuligheder
Indstillinger ✅
Beskrivelse af mulighederne:
“The Design and Supply Contract has the following options (“Options”), cf. section 6 of the Design and Supply Contract.
• Option 1: Additional frequency...”
Beskrivelse af mulighederne
The Design and Supply Contract has the following options (“Options”), cf. section 6 of the Design and Supply Contract.
• Option 1: Additional frequency converter capacity needed to reach a total capacity of at least 48 MVA measured as a sum at the ship connection plugs. The added frequency converters and their auxiliary equipment shall have same specifications as the equipment supplied in the basic scope.
• Option 2: One additional mobile cable system crane, rated to 16 MVA, available at Oceankaj with possibility to connect to any of the shore side terminal boxes O-T1, O-T2, O-T3. The additional mobile cable system crane vehicles shall have same specifications as the equipment supplied in the basic scope.
• Option 3: The Service & Maintenance Agreement has a duration of 2 years with an option to increase with a duration of 1 year for three times, i.e. af total duration for up to 5 years.
• Option 4: Additional earthing switch housing and required cabling from earthing switch housing and to CMS and CMS solution at Langelinie at a capacity of 16 MVA.
Vis mere Omfanget af udbuddet
Oplysninger om EU-midler: 2019-EU-TM-0125-W
Beskrivelse
Yderligere oplysninger: Action title: Coordinated Supply of Onshore Power in Baltic Seaports
Juridiske, økonomiske, finansielle og tekniske oplysninger Økonomisk og finansiel stilling
Liste og kortfattet beskrivelse af udvælgelseskriterier:
“The candidate have to fill in the following information to the ESPD:
• The candidate's turnover during each of the 2 most recent completed and audited...”
Liste og kortfattet beskrivelse af udvælgelseskriterier
The candidate have to fill in the following information to the ESPD:
• The candidate's turnover during each of the 2 most recent completed and audited financial reports.
• The candidate's equity in the most recent completed and audited financial report.
• The candidate's solvency ratio (equity to assets) in the most recent completed and audited financial report.
“• The tenderer must have a yearly turnover of at least DKK 140.000.000 excl. VAT during each of the past 2 most recent completed and audited financial...”
• The tenderer must have a yearly turnover of at least DKK 140.000.000 excl. VAT during each of the past 2 most recent completed and audited financial reports.
• The tenderer must have an equity of at least DKK 15.000.000 in the most recent completed and audited financial report.
• The tenderer must have a solvency ratio (equity to assets) of at least 20 % in the most recent completed and audited financial report.
Vis mere Teknisk og faglig kompetence
Liste og kortfattet beskrivelse af udvælgelseskriterier: -
Betingelser i forbindelse med kontrakten
Betingelser for opfyldelse af kontrakten:
“The contract contains a labour clause and a social clause. Furthermore, the contract stipulates liquidated damages for certain delays and failure to meet...”
Betingelser for opfyldelse af kontrakten
The contract contains a labour clause and a social clause. Furthermore, the contract stipulates liquidated damages for certain delays and failure to meet performance requirements.
Vis mere Oplysninger om det personale, der er ansvarligt for kontraktens udførelse
Pligt til at oplyse navn og faglige kvalifikationer for det personale, der er udpeget til at udføre kontrakten
Procedure Type af procedure
Åben procedure
Administrative oplysninger
Frist for modtagelse af bud eller ansøgninger om deltagelse: 2023-08-04
12:00 📅
Sprog, på hvilke bud eller ansøgninger om deltagelse kan indgives: engelsk 🗣️
Nedenstående tidsramme er udtrykt i antal måneder.
Minimumsfrist, inden for hvilken tilbudsgiveren skal opretholde tilbuddet: 3
Betingelser for åbning af buddene: 2023-08-04
15:00 📅
Betingelser for åbning af tilbud (Oplysninger om bemyndigede personer og åbningsprocedure): Tenderers do not have access to attend the opening of tenders.
Supplerende oplysninger Oplysninger om elektroniske arbejdsgange
Elektronisk fakturering vil blive accepteret
Der vil blive anvendt elektronisk betaling
Yderligere oplysninger
“The Contracting Authority will exclude economic operators who are covered by one or more of the voluntary grounds for exclusion in section 137(1), number...”
The Contracting Authority will exclude economic operators who are covered by one or more of the voluntary grounds for exclusion in section 137(1), number (2) or (6) of the Danish Public Procurement Act.
As documentation of the fact that the tenderer is not subject to the grounds for exclusion, the Contracting Authority will accept the following:
• An extract from the relevant register or a similar document issued by a competent judicial or administrative authority stating that the candidate or tenderer is not subject to the grounds for exclusion stipulated in section 135(1).
• A certificate issued by the competent authority in the country referred to as documentation that the candidate is not subject to the grounds for exclusion stipulated in the cases stated in section 135(3) and section 137(1)(2 or 6).
If the country in question does not issue the documents or certificates, or if such documents or certificates do not cover all the cases mentioned in section 135(1) or (3) and section 137(1)(2 or 6), those documents or certificates can be replaced by a statement provided on oath. If statements on oath are not provided for in the relevant country, a solemn declaration made before a competent judicial or administrative authority, a notary or a competent professional organisation in the country in which the tenderer is registered can be applied.
For tenderers registered in Denmark, this documentation can be in the form of a service certificate issued by the Danish Business Authority on request. This also applies in case the tenderer has foreign members in the board, management or supervisory committee.
For tenderers registered outside Denmark, please be aware of the listed relevant documentation in e-certis, which will be sufficient: https://ec.europa.eu/growth/tools-databases/ecertis/.
The Contracting Authority will accept sufficient documentation from national authorities in the national language. The Contracting Authority requests this documentation to be unofficially translated into English.
Documentation must not have been issued earlier than 6 months prior to the deadline of submission of tender.
As documentation that the tenderer meets the requirements for suitability specified in section 6.2.3, the tenderer will be asked to submit:
• Audited annual accounts or extracts thereof, showing the tenderer's annual turnover and equity in the most recently completed and audited financial reports at the deadline of submission of the tender.
The tenderer may document its fulfilment of the minimum requirements for economic and financial standing by any other document that the Contracting Authority deems appropriate if the tenderer for a valid reason is unable to submit the above documents or is unable to document one or more of the minimum requirements by the audited annual accounts.
In addition, the tenderer is not obliged to provide documentation for information that the Contracting Authority can obtain itself in a national database. In this case, however, the tenderer must state where this documentation can be found.
If the tenderer is a group of economic operators (e.g. a consortia), documentation in relation to both grounds for exclusion and suitability must be submitted for each of the entities in the group.
If the tenderer relies on the economic and financial standing and /or technical and professional ability of one or more entities, documentation for reasons of exclusion and relevant documentation of suitability must also be submitted for each of the supporting entities.
Vis mere Gennemgå organ
Navn: Klagenævnet for Udbud
Postadresse: Toldboden 2
Postby: Viborg
Postnummer: 8800
Land: Danmark 🇩🇰
Telefon: +45 72405600📞
E-mail: klfu@naevneneshus.dk📧
URL: https://naevneneshus.dk/start-din-klage/klagenaevnet-for-udbud/🌏 Gennemgangsprocedure
Præcise oplysninger om fristerne for gennemgangsprocedurer:
“The Danish Complaints Board for Public Procurement Act (Act no. 593 of 02.06.2016 which is available atwww.retsinformation.dk.) contains the regulation...”
Præcise oplysninger om fristerne for gennemgangsprocedurer
The Danish Complaints Board for Public Procurement Act (Act no. 593 of 02.06.2016 which is available atwww.retsinformation.dk.) contains the regulation governing deadlines for review procedures regarding public procurement under Danish law. Complaints must be lodged with the Complaints Board within a 45 calendar day deadline initiated by CPH City & Port I/S’ publication of a contract award notice in the Official Journal of the European Union. The first day of the deadline is the day following the publication date, cf. section 7(2)(i) of the Danish Complaints Board for Public Procurement Act.
The complainant must notify CPH City & Port I/S of the complaint in writing at the latest at the same time as the complainant lodges the complaint with the Complaints Board. Furthermore, the complainant must inform CPH City & Port I/S as to whether or not the complaint has been lodged in the standstill-period and whether the complainant has requested the complaint to be given suspensory effect, cf. section 6(4) of the Danish Complaints Board for Public Procurement Act.
To lodge a complaint with the Danish Complaints Board for Public Procurement the complainant must pay a fee of DKK 20,000.
Vis mere Tjeneste, hvorfra der kan indhentes oplysninger om klageproceduren
Navn: Konkurrence- og Forbrugerstyrelsen
Postadresse: Carl Jacobsens Vej 35
Postby: Valby
Postnummer: 2500
Land: Danmark 🇩🇰
Telefon: +45 41715000📞
E-mail: kfst@kfst.dk📧
URL: www.kfst.dk🌏
Kilde: OJS 2023/S 103-323741 (2023-05-26)
Supplerende oplysninger (2023-07-17)
Supplerende oplysninger Oprindelig reference til meddelelsen
Meddelelsesnummer i EUT S: 2023/S 103-323741
Ændringer Tekst, der skal berigtiges i den oprindelige meddelelse
Afsnittets nummer: II.2.7
Gammel værdi
Dato: 2025-03-06 📅
Ny værdi
Dato: 2025-04-30 📅
Tekst, der skal berigtiges i den oprindelige meddelelse
Afsnittets nummer: II.2.11
Gammel værdi
Tekst:
“The Design and Supply Contract has the following options (“Options”), cf. section 6 of the Design and Supply Contract.
• Option 1: Additional frequency...”
Tekst
The Design and Supply Contract has the following options (“Options”), cf. section 6 of the Design and Supply Contract.
• Option 1: Additional frequency converter capacity needed to reach a total capacity of at least 48 MVA measured as a sum at the ship connection plugs. The added frequency converters and their auxiliary equipment shall have same specifications as the equipment supplied in the basic scope.
• Option 2: One additional mobile cable system crane, rated to 16 MVA, available at Oceankaj with possibility to connect to any of the shore side terminal boxes O-T1, O-T2, O-T3. The additional mobile cable system crane vehicles shall have same specifications as the equipment supplied in the basic scope.
• Option 3: The Service & Maintenance Agreement has a duration of 2 years with an option to increase with a duration of 1 year for three times, i.e. af total duration for up to 5 years.
• Option 4: Additional earthing switch housing and required cabling from earthing switch housing and to CMS and CMS solution at Langelinie at a capacity of 16 MVA.
Vis mere Ny værdi
Tekst:
“The Design and Supply Contract has the following options (“Options”), cf. section 6 of the Design and Supply Contract.
• Option 1: Additional frequency...”
Tekst
The Design and Supply Contract has the following options (“Options”), cf. section 6 of the Design and Supply Contract.
• Option 1: Additional frequency converter capacity needed to reach a total capacity of at least 48 MVA measured as a sum at the ship connection plugs. The added frequency converters and their auxiliary equipment shall have same specifications as the equipment supplied in the basic scope.
• Option 2: One additional mobile cable system crane, rated to 16 MVA, available at Oceankaj with possibility to connect to any of the shore side terminal boxes O-T1, O-T2, O-T3. The additional mobile cable system crane vehicles shall have same specifications as the equipment supplied in the basic scope.
• Option 3: The Service & Maintenance Agreement has a duration of 2 years with an option to increase with a duration of 1 year for three times, i.e. af total duration for up to 5 years.
Vis mere Tekst, der skal berigtiges i den oprindelige meddelelse
Afsnittets nummer: IV.2.2
Gammel værdi
Dato: 2023-08-04 📅
Tid: 12:00
Ny værdi
Dato: 2023-08-11 📅
Tid: 12:00
Kilde: OJS 2023/S 139-440861 (2023-07-17)