New Hans Christian Andersen Museum is inviting tenders for the Setworks Contractor for New Hans Christian Andersen Museum. The Setworks package includes the following:
— setworks (including integrated lighting and graphics),
— track lighting (including control system and programming) (Option cf. II.2.11),
— canopies,
— seating (Option cf. II.2.11),
— power/data extensions for this and other packages appointed by the client,
— prototype/mock up and samples.
The full tender material is available on www.rib-software.dk/udbudsportal and the TN-number of the tender is TN 993377A.
Deadline
Fristen for modtagelse af bud var på 2019-08-08.
Indkøbet blev offentliggjort på 2019-07-08.
Leverandører
Følgende leverandører er nævnt i tildelingsbeslutninger eller andre indkøbsdokumenter:
Udbudsbekendtgørelse (2019-07-08) Ordregivende myndighed Navn og adresser
Navn: Odense Kommune
Nationalt registreringsnummer: 35209115
Postadresse: Flakhaven 2
Postby: Odense C
Postnummer: 5000
Land: Danmark 🇩🇰
Kontaktperson: Charlotte Trillingsgaard
E-mail: cbtri@odense.dk📧
Region: Fyn🏙️
URL: http://www.odense.dk/🌏 Kommunikation
URL til dokumenter: www.rib-software.dk/udbudsportal🌏
Objekt Omfanget af udbuddet
Titel: Setworks Package for the New Hans Christian Andersen Museum
Produkter/tjenester: Bygge- og anlægsarbejder📦
Kort beskrivelse:
“New Hans Christian Andersen Museum is inviting tenders for the Setworks Contractor for New Hans Christian Andersen Museum. The Setworks package includes the...”
Kort beskrivelse
New Hans Christian Andersen Museum is inviting tenders for the Setworks Contractor for New Hans Christian Andersen Museum. The Setworks package includes the following:
— setworks (including integrated lighting and graphics),
— track lighting (including control system and programming) (Option cf. II.2.11),
— canopies,
— seating (Option cf. II.2.11),
— power/data extensions for this and other packages appointed by the client,
— prototype/mock up and samples.
The full tender material is available on www.rib-software.dk/udbudsportal and the TN-number of the tender is TN 993377A.
Vis mere
Anslået værdi uden moms: DKK 23 000 000 💰
1️⃣
Yderligere produkter/tjenester: Belysningsudstyr og elektriske lamper📦
Yderligere produkter/tjenester: Opførelse af museer📦
Yderligere produkter/tjenester: Grafisk design📦
Yderligere produkter/tjenester: Sæder📦
Sted for udførelsen: Fyn🏙️
Hovedsted eller sted for udførelsen: Odense.
Beskrivelse af udbuddet:
“The setworks contractor scope of works shall include but is not limited to:
Coordinated fabrication and installation of the exhibition displays with full...”
Beskrivelse af udbuddet
The setworks contractor scope of works shall include but is not limited to:
Coordinated fabrication and installation of the exhibition displays with full responsibility for the setworks timeframe and coordinating and liaising with the the client, the building consultant team, building contractors and other exhibition package contractors. the setworks contractor shall Deliver a complete setworks project, understanding that the client’s requirement is for a complete and cohesive system.
Be responsible for the technical design and performance of all structural and non-structural members, joining techniques, mechanical operations and structural stability of the elements of the components and their interface with each other and the building.
Be fully responsible for all aspects of delivery and installation including parking, unloading, handling and transportation of the works and disposal of all packaging and surplus materials.
Provide site management for the setworks, project management, design development, fabrication, installation, commissioning, documentation and user training.
The Contract is envisaged to start in October 2019 and end early 2021 but the exact dates depend on the construction and finalisation of the building. This means that the the contract period may be longer or end at a later time than described in Section II.2.7 and in the tender material and that the milestones in the tender material may be altered/postponed during the course of the procurement and the contract period.
Vis mere Kriterier for tildeling
Prisen er ikke det eneste tildelingskriterium, og alle kriterier er kun anført i udbudsdokumenterne
Omfanget af udbuddet
Anslået samlet værdi ekskl. moms: DKK 23 000 000 💰
Varighed
Startdato: 2019-10-20 📅
Slutdato: 2021-01-30 📅
Oplysninger om begrænsningerne i antallet af ansøgere, der kan indbydes
Påtænkt antal ansøgere: 3
Objektive kriterier for udvælgelse af det begrænsede antal ansøgere:
“The limitation of applicants will be based on an evaluation of which candidates have documented the most relevant previous deliveries compared to the...”
Objektive kriterier for udvælgelse af det begrænsede antal ansøgere
The limitation of applicants will be based on an evaluation of which candidates have documented the most relevant previous deliveries compared to the elements described in Section II.1.4 and II.2.4. The evaluation of this will be made based on the information on technical ability described in Section III.1.3
In this evaluation references showing previous experiences with all or the majority of the elements described in Section II.1.4 and II.2.4 (including setworks and theming incl. scenic artist, graphics, lighting, physical interactives, and coordination/collaboration with artists, showcases, audio visual hardware and audio visual software) will be weighted more positively than other references.
References of a high technical quality will be weighted more positively than references with lower technical quality. The technical quality is assessed based on the responses to Section III.1.3 elements iii) — ix) that should illustrate to which extent the applicant has insight and experience in handling setworks processes with a high degree of complexity and with a high degree of collaboration and interaction with the client and other stakeholders while meeting the contractual requirements.
It is weighted positively if the references show that the applicant has performed these services in different countries.
Please note that any ambiguities and/or incomprehensibilities in the information submitted under Section III.1.3 may be regarded negatively in the evaluation when selecting the limited numbers of candidates.
Vis mere Oplysninger om valgmuligheder
Indstillinger ✅
Beskrivelse af mulighederne: — seating,
— Track lighting.
Beskrivelse
Yderligere oplysninger:
“Odense Kommune has decided not to divide the contract into lots as this is expected to unduly increase the cost as well as the risk regarding the...”
Yderligere oplysninger
Odense Kommune has decided not to divide the contract into lots as this is expected to unduly increase the cost as well as the risk regarding the integration of the different deliveries under the contract.
Juridiske, økonomiske, finansielle og tekniske oplysninger Økonomisk og finansiel stilling
Liste og kortfattet beskrivelse af udvælgelseskriterier:
“1) The applicant must submit information on the applicant’s annual turnover for the last 3 financial years. The information shall be stated in the European...”
Liste og kortfattet beskrivelse af udvælgelseskriterier
1) The applicant must submit information on the applicant’s annual turnover for the last 3 financial years. The information shall be stated in the European Single Procurement Document (ESPD), Part IV.B ‘General yearly turnover’, cf. Section VI.3 below;
2) The applicant shall provide information on the company’s equity for the last 3 financial years. The information shall be stated in the European Single Procurement Document, Part IV.B ‘Financial key figures’, cf. Section VI.3 below. In the event Odense Kommune requires documentation for the above the applicant must provide the 3 latest audited annual financial reports. If these are not in English or Scandinavian, the applicant is asked to also provide a resume in English.
Reference is made to Section VI.3 with regard to the applicant's possibility of relying on the capacity of other entities.
“1) The applicant must have achieved an annual turnover of at least 40 000 000 DKK, in each of the preceding 3 financial years. If the turnover is not stated...”
1) The applicant must have achieved an annual turnover of at least 40 000 000 DKK, in each of the preceding 3 financial years. If the turnover is not stated in said currency, Odense Kommune will calculate the turnover based on the official exchange rate on the date this notice was published;
2) The applicant must have achieved a positive equity in each of the preceding 3 financial years. In the event that the applicant’s equity in any of the last 3 years is below zero, the applicant will be excluded.
Vis mere Teknisk og faglig kompetence
Liste og kortfattet beskrivelse af udvælgelseskriterier:
“1) A list of the applicant's 3 most important deliveries within the last 5 years from similar contracts containing a majority of the works described under...”
Liste og kortfattet beskrivelse af udvælgelseskriterier
1) A list of the applicant's 3 most important deliveries within the last 5 years from similar contracts containing a majority of the works described under Section II.1.4 and II.2.4.
The list should preferably include the following information on each reference:
(i) description of the project including project value and client details and client brief including details of what was provided;
(ii) relevance of experience shown in relation to setworks and theming inc scenic artist, graphics, lighting, physical interactives, and coordination/collaboration with artists, showcases, audio visual hardware and audio visual software;
(iii) details regarding the process and procedures that were used to ensure the highest levels of quality are achieved on your project;
(iv) details regarding the methodology used for the development of the projects during the pre-construction and off-site fabrication period complete with details of the level and type of personnel involved during this period;
(v) details of how you collaborated with the basebuild consultants and contractors through each stage of the project, highlight M&E and structural interfaces;
(vi) details regarding how you managed the delivery of the project on site logistically for your own and any sub-contractor and suppliers including details of how you would address any anticipated challenges of working in this location, along with proven collaboration and coordination with other client direct packages;
(vii) specific working methods for providing, maintaining and monitoring a high level of service delivery and customer satisfaction;
(viii) details of meetings, communications and interactions between all parties to ensure efficient project completion;
(ix) description of approach to handover, including awareness training of all relevant persons involved.
The information shall be stated in the European Single Procurement Document, Part IV, cf. section VI.3 below or in a separate document with clear indication that this document is an answer to the tender notice, Section III.3.
Reference is made to section VI.3 with regard to the candidate's possibility of relying on the capacity of other entities.
Vis mere Betingelser for deltagelse
Betingelser for deltagelse (tekniske og faglige kvalifikationer):
“1) The applicant must with a minimum of 1 reference demonstrate experience with the delivery of a majority of the works described under Section II.1.4 and II.2.4.”
Betingelser for deltagelse (tekniske og faglige kvalifikationer)
1) The applicant must with a minimum of 1 reference demonstrate experience with the delivery of a majority of the works described under Section II.1.4 and II.2.4.
Procedure Type af procedure
Konkurrencepræget procedure med forhandling
Oplysninger om forhandling
Den ordregivende myndighed forbeholder sig ret til at tildele kontrakten på grundlag af de første tilbud uden at føre forhandlinger
Administrative oplysninger
Frist for modtagelse af bud eller ansøgninger om deltagelse: 2019-08-08
11:00 📅
Sprog, på hvilke bud eller ansøgninger om deltagelse kan indgives: engelsk 🗣️
Nedenstående tidsramme er udtrykt i antal måneder.
Minimumsfrist, inden for hvilken tilbudsgiveren skal opretholde tilbuddet: 3
Supplerende oplysninger Yderligere oplysninger
“Applicants who wish to participate in this tender process must fill in the ESPD via Byggeweb. Complete the ESPD with the information specified in the...”
Applicants who wish to participate in this tender process must fill in the ESPD via Byggeweb. Complete the ESPD with the information specified in the Contract Notice, including Part II.A, II.B, II.C, III.A, III.B, III.C, IV.B and IV.C.
Note that the applicant must submit several ESPDs, if the applicant forms an association of companies or is based on the capacity of other economic operators.
Applicant must in the ESPD state the name, VAT/CVR number, postal address, contact person whether the applicant is a micro-enterprise, small or medium-sized enterprise and whether the applicant participates in the tender procedure with others (ESPD Part II.A). The applicant must provide the information requested in Part III of the Contract Notice. The applicant must confirm that the applicant is not covered by the compulsory exclusion grounds in Sections 135 and 136 of the Danish Public Procurement Act (ESPD Part III, Paragraphs A, B and C). In addition, the applicant must confirm that the applicant is not covered by the voluntary exclusion grounds in Section 137 Sub-section 1, 2 and 5 of the Danish Public Procurement Act (ESPD Part III, Section C). The requested information forms the basis of the Contracting Authority's assessment of whether the applicant is suitable for carrying out the deliverables of the tender and which applicants are invited to submit a tender. If the applicant participates in the tendering procedure with others, in particular as part of a group, consortium, joint venture or the like, all affected participants must submit a separate ESPD. All required information under Part III must be provided for each participant in the consortium. In connection with the suitability assessment, however, it will be the consortium's overall suitability that is assessed. If the required information is not provided by all consortium participants, the offer is not necessarily non-compliant, but it may affect the suitability assessment. In addition, each participant in the individual ESPD must indicate the role of the economic operator in the group, the other economic operators participating in the procedure and, where appropriate, the name of the participating group (ESPD Part II.A). If the applicant is unable to meet the requirements of financial and economic and/or technical and professional capacity, the applicant may rely on the financial and economic and/or technical and professional capacity of other entities. In this case, any sub-contractors of the applicant must also enclose a separate ESPD with completed Part II, sections A and B and Part III duly completed by the entities concerned (ESDP Part II, Section C). In connection with the suitability assessment, it will be the total suitability that is assessed, including by combining key figures.
The applicant can only submit to be application for pre-qualification. If the same legal entity is part of or otherwise participates in several applications, e.g. submitting its own application, but at the same time being a participant in consortium or the like applying, the applicants must ensure that the participation of the same legal entity does not entail the possibility of mutually influencing the contant of the various tenderers' offers. Application for pre-qualification must be submitted electronically to Byggeweb, cf. Section I.3 of the Contract Notice.
Vis mere Gennemgå organ
Navn: Klagenævnet for Udbud
Postadresse: Nævnenes Hus, Toldboden 2
Postby: Viborg
Postnummer: 8800
Land: Danmark 🇩🇰
Telefon: +45 72405708📞
E-mail: klfu@naevneneshus.dk📧
URL: https://www.erhvervsstyrelsen.dk/klagenaevnet-for-udbud🌏 Gennemgangsprocedure
Præcise oplysninger om fristerne for gennemgangsprocedurer:
“According to the Danish Act on the Complaints Board for Procurement, etc. (LBK No 593 of 2.6.2016), the following deadlines apply for submission of...”
Præcise oplysninger om fristerne for gennemgangsprocedurer
According to the Danish Act on the Complaints Board for Procurement, etc. (LBK No 593 of 2.6.2016), the following deadlines apply for submission of complaint:
Complaints about not being pre-qualified must be submitted to the complaints board for procurement within 20 calendar days from the day after the day on which the Contracting Authority has sent a notification to the affected applicants about who has been pre-qualified if the notification has stated a brief account of the relevant reasons for the decision, cf. § 7(1) of the said act.
Complaints about the award of the contract must be made to the complaints board within 45 days after the Contracting Authority has published a notice in the Official Journal of the European Union stating that the Contracting Authority has concluded a contract. The deadline is calculated from the day on which the notice is published.
Not later than the time a complaint is lodged with the complaints board for invitation to tender, the complainant must notify the Contracting Authority in writing that the complaint has been submitted to the complaints board for procurement and whether the complaint has been filed in the standstill period, cf. § 6(4). In cases where the complaint has not been lodged during the standstill period, the complainant must also indicate whether a suspensive effect is requested from the complaint, cf. § 12(1).
Vis mere Tjeneste, hvorfra der kan indhentes oplysninger om klageproceduren
Navn: Konkurrence- og Forbrugerstyrelsen
Postadresse: Carl Jacobsens Vej 35
Postby: Valby
Postnummer: 2500
Land: Danmark 🇩🇰
Telefon: +45 41715000📞
E-mail: kfst@kfst.dk📧
URL: http://www.kfst.dk🌏
Kilde: OJS 2019/S 132-323196 (2019-07-08)
Bekendtgørelse om indgåede kontrakter (2020-07-10) Objekt Omfanget af udbuddet
Kort beskrivelse:
“New Hans Christian Andersen Museum is inviting tenders for the Setworks contractor for New Hans Christian Andersen Museum. The Setworks package includes the...”
Kort beskrivelse
New Hans Christian Andersen Museum is inviting tenders for the Setworks contractor for New Hans Christian Andersen Museum. The Setworks package includes the following:
• Setworks (including integrated lighting and graphics),
• track lighting (inc control system and programming) (Option cf. II.2.11),
• canopies,
• seating (Option cf. II.2.11),
• power/data extensions for this and other packages appointed by the client,
• prototype/mock up and samples.
The full tender material is available on www.rib-software.dk/udbudsportal and the TN-number of the tender is TN 993377A.
Vis mere
Samlet værdi af indkøbsaftalen (ekskl. moms): DKK 22 383 795 💰
Beskrivelse
Beskrivelse af udbuddet:
“The Setworks contractor scope of works shall include but is not limited to:
Coordinated fabrication and installation of the exhibition displays with full...”
Beskrivelse af udbuddet
The Setworks contractor scope of works shall include but is not limited to:
Coordinated fabrication and installation of the exhibition displays with full responsibility for the Setworks timeframe and coordinating and liaising with the the client, the building consultant team, building contractors and other exhibition package contractors. the Setworks contractor shall deliver a complete Setworks project, understanding that the client’s requirement is for a complete and cohesive system.
Be responsible for the technical design and performance of all structural and non-structural members, joining techniques, mechanical operations and structural stability of the elements of the components and their interface with each other and the building.
Be fully responsible for all aspects of delivery and installation including parking, unloading, handling and transportation of the works and disposal of all packaging and surplus materials.
Provide site management for the Setworks, project management, design development, fabrication, installation, commissioning, documentation and user training.
The contract is envisaged to start in October 2019 and end early 2021 but the exact dates depend on the construction and finalisation of the building. This means that the the contract period may be longer or end at a later time than described in Section II.2.7) and in the tender material and that the milestones in the tender material may be altered/postponed during the course of the procurement and the contract period.
Vis mere Kriterier for tildeling
Kvalitetskriterium (navn): Organisation
Kvalitetskriterium (vægtning): 15 %
Kvalitetskriterium (navn): Time schedule
Kvalitetskriterium (navn): Specific design and quality
Kvalitetskriterium (vægtning): 25 %
Kvalitetskriterium (navn): Handover and soft landings
Kvalitetskriterium (vægtning): 5 %
Pris (justeringskoefficient): 40 %
Oplysninger om valgmuligheder
Beskrivelse af mulighederne: — seating,
— track lighting.
Procedure Administrative oplysninger
Tidligere offentliggørelse vedrørende denne procedure: 2019/S 132-323196
Tildeling af kontrakt
1️⃣
Titel: Setworks Package for the New Hans Christian Andersen Museum
Dato for indgåelse af kontrakten: 2020-07-02 📅
Oplysninger om udbud
Antal modtagne bud: 3
Antal modtagne bud fra SMV'er: 3
Antal modtagne bud fra tilbudsgivere fra andre EU-medlemsstater: 1
Antal modtagne bud fra bydende fra lande uden for EU: 2
Antal bud, der er modtaget ad elektronisk vej: 3
Navn og adresse på kontrahenten
Navn: The Hub Consulting Ltd
Nationalt registreringsnummer: 05629190
Postadresse: The Hub, 48a Heming Road, Washford Industrial Estate, Redditch
Postby: Worcerstershire
Postnummer: B98 0EA
Land: Storbritannien 🇬🇧
Region: Worcestershire 🏙️
Entreprenøren er en SMV ✅ Oplysninger om kontraktens/parcellens værdi (ekskl. moms)
Anslået samlet værdi af kontrakten/partiet: DKK 23 000 000 💰
Kontraktens/parcellens samlede værdi: DKK 22 383 795 💰
Supplerende oplysninger Gennemgangsprocedure
Præcise oplysninger om fristerne for gennemgangsprocedurer:
“According to the Danish Act on the Complaints Board for Procurement, etc. (LBK No 593 of 2 June 2016), the following deadlines apply for submission of...”
Præcise oplysninger om fristerne for gennemgangsprocedurer
According to the Danish Act on the Complaints Board for Procurement, etc. (LBK No 593 of 2 June 2016), the following deadlines apply for submission of complaint:
Complaints about the award of the contract must be made to the Complaints Board within 45 days after the contracting authority has published a notice in the Official Journal of the European Union stating that the contracting authority has concluded a contract. The deadline is calculated from the day on which the notice is published.
Not later than the time a complaint is lodged with the Complaints Board for invitation to tender, the complainant must notify the contracting authority in writing that the complaint has been submitted to the Complaints Board for Procurement and whether the complaint has been filed in the standstill period, cf. § 6(4). In cases where the complaint has not been lodged during the standstill period, the complainant must also indicate whether a suspensive effect is requested from the complaint, cf. § 12(1).
Vis mere Tjeneste, hvorfra der kan indhentes oplysninger om klageproceduren
Navn: Konkurrence-og Forbrugerstyrelsen
Kilde: OJS 2020/S 134-328545 (2020-07-10)