NE Korskro — Supply of Machinery and Electrical Equipment

NGF Nature Energy Korskro A/S

The scope includes the supply of machinery and erection of machinery and other mechanical, electrical and electronic equipment to biogas plant including:
— Design, supply, construction, erection, equipment for controlling, regulating and monitoring (SCADA) of process equipment, commissioning, testing for performance, certification, instruction and training of the operator's personnel in the operation and maintenance of the Works prior to take-over.
— Documentation and authority processing and necessary permits and approvals.
The scope shall include all ancillary and auxiliary equipment and systems, interconnecting piping, cabling, instrumentation and interface work with upstream or downstream facilities, the provision of all labour, materials, Contractor's equipment, temporary works, and everything whether of a temporary or permanent nature, required to provide a complete working installation meeting the performance parameters defined in the Contract and otherwise agreed between the two parties and providing all of the facilities necessary for the operation and maintenance of the installations and the Site on which the installations are situated.
The Contractor shall hand over the project and demonstrate its performance whilst the Plant is operated by the Employer's staff under the supervision of the Contractor, including training of the Employer's staff and personnel in accordance with prudent operating and maintenance practices, carrying out of all Tests as defined in the Technical Conditions, all in accordance with established technical principles and in accordance with the Technical Conditions and to the satisfaction of the Employer.
The evaluation will be based on plant price, operation cost and guarantees for capacity and consumables.

Deadline

Fristen for modtagelse af bud var på 2017-08-04. Indkøbet blev offentliggjort på 2017-07-07.

Leverandører

Følgende leverandører er nævnt i tildelingsbeslutninger eller andre indkøbsdokumenter:

Hvem? Hvad? Hvor?
Indkøbshistorik
Dato Dokument
2017-07-07 Udbudsbekendtgørelse
2017-11-29 Bekendtgørelse om indgåede kontrakter
Udbudsbekendtgørelse (2017-07-07)
Objekt
Omfanget af udbuddet
Titel: Bygge-anlægsarbejde: gasproduktionsanlæg
Mængde eller omfang: Supply of Machinery and Electrical Equipment as specified in tender document.
Bekendtgørelsens metadata
Originalsprog: engelsk 🗣️
Dokumenttype: Udbudsbekendtgørelse
Kontraktens art: Bygge og anlæg
Forordning: Den Europæiske Union
Fælles glossar for offentlige kontrakter (CPV)
Kode: Bygge-anlægsarbejde: gasproduktionsanlæg 📦

Procedure
Procedureform: Udbud efter forhandling
Bud-type: Indsendelse gældende for alle delaftaler
Kriterier for tildeling
Det økonomisk mest fordelagtige bud

Ordregivende myndighed
Identitet
Land: Danmark 🇩🇰
Type af ordregivende myndighed: Forsyningsvirksomhed
Navn på ordregivende myndighed: NGF Nature Energy Korskro A/S
Postadresse: Ørbækvej 260
Postnummer: 5220
Postby: Odense SØ
Kontakt
Internetadresse: http://www.natureenergy.dk 🌏
E-mail: lsk@natureenergy.dk 📧
Telefon: +45 21647840 📞

Reference
Datoer
Afsendelsesdato: 2017-07-07 📅
Tilbudsfrist: 2017-08-04 📅
Offentliggørelsesdato: 2017-07-13 📅
Identifikatorer
Bekendtgørelsesnummer: 2017/S 132-271175
EUT-S-nummer: 132
Yderligere oplysninger
NGF Nature Energy Korskro intends to invite a maximum of 6 applicants to tender. The applicant may only submit one request for this tender. The ESPD-document is uploaded to the tender document and shall be completed online in XML-format.

Objekt
Omfanget af udbuddet
Kort beskrivelse:
The scope includes the supply of machinery and erection of machinery and other mechanical, electrical and electronic equipment to biogas plant including:
— Design, supply, construction, erection, equipment for controlling, regulating and monitoring (SCADA) of process equipment, commissioning, testing for performance, certification, instruction and training of the operator's personnel in the operation and maintenance of the Works prior to take-over.
Vis mere
— Documentation and authority processing and necessary permits and approvals.
The scope shall include all ancillary and auxiliary equipment and systems, interconnecting piping, cabling, instrumentation and interface work with upstream or downstream facilities, the provision of all labour, materials, Contractor's equipment, temporary works, and everything whether of a temporary or permanent nature, required to provide a complete working installation meeting the performance parameters defined in the Contract and otherwise agreed between the two parties and providing all of the facilities necessary for the operation and maintenance of the installations and the Site on which the installations are situated.
Vis mere
The Contractor shall hand over the project and demonstrate its performance whilst the Plant is operated by the Employer's staff under the supervision of the Contractor, including training of the Employer's staff and personnel in accordance with prudent operating and maintenance practices, carrying out of all Tests as defined in the Technical Conditions, all in accordance with established technical principles and in accordance with the Technical Conditions and to the satisfaction of the Employer.
Vis mere
The evaluation will be based on plant price, operation cost and guarantees for capacity and consumables.
Beskrivelse af mulighederne: Specified in tender documents.
Referencenummer: 6060-ANL-007

Juridiske, økonomiske, finansielle og tekniske oplysninger
Betingelser for deltagelse
Egnethed til at udøve det erhverv:
In order to be prequalified to participate in this tender, applicants must fill in ESPD as preliminary evidence of that they are not in one of the following situations:
A: Relating to criminal convictions: Participation in a criminal organisation, Corruption, Fraud, Terrorist offences or offences linked to terrorist activities, Money laundering or terrorist financing, Child labour and other forms of trafficking in human beings;
Vis mere
B: Has not fulfilled its obligations relating to the payment of taxes or social security contributions;
C: Relating to insolvency, conflicts of interests or professional misconduct — Breaching of obligations in the field of environmental law, Breaching of obligations in the field of social law, Breaching of obligations in the fields of labour law, Bankruptcy, Insolvency, Arrangement with creditors, Analogous situation like bankruptcy under national law, Assets being administered by liquidator, Business activities are suspended, Guilty of grave professional misconduct, Agreements with other economic operators aimed at distorting competition, Conflict of interest due to its participation in the procurement procedure, Direct or indirect involvement in the preparation of this procurement procedure, Early termination, damages or other comparable sanctions, Guilty of misinterpretation, withheld information or unable to provide required documents and obtained confidential information of this procedure.
Vis mere
For applicants registered in Denmark evidence can be proven by a ‘Service Attest’ (service certificate) from the Danish Commerce and Companies Agency. A similar certificate issued by the competent authority in the Member State concerned is also considered proof of evidence. Where the country in question does not issue such documents or certificates, or where these do not cover all the cases specified above, they may be replaced by a declaration on oath or, in Member States where there is no provision for declarations on oath, by a solemn declaration made by the person concerned before a competent judicial or administrative authority, a notary or a competent professional or trade body, in the country of origin or in the country whence that person comes.
Vis mere
Service certificate or all other of the possible required statements to the above may not be more than six month old at the time of bidding.
Økonomisk og finansiel stilling:
In order to be prequalified to participate in this tender, applicants must fill in ESPD as preliminary evidence of Economic and financial standing:
A: General yearly turnover, Specific yearly turnover, Financial ratio, Professional risk and indemnity insurance.
Teknisk og faglig kompetence:
Applicants must fill in ESPD as preliminary evidence of Technical and professional ability:
A: For works contracts: performance of works of the specified type, Technicians or technical bodies for quality control, For works contracts: technicians or technical bodies to carry out the work, Educational and professional qualifications, Average annual manpower and Subcontracting proportion;
Vis mere
B: Certificates by independent bodies about quality assurance standards.
Kontraktens udførelse
Krav om deponering og sikkerhedsstillelse:
The Contractor shall submit an Advance Payment Guarantee for any sums paid in advance and a Performance Guarantee equivalent to a percentage of the contract value (15 %).
De vigtigste finansieringsbetingelser og betalingsordninger og/eller henvisning til de relevante bestemmelser, der regulerer dem: The payment will be in Danish kroner.

Procedure
Sprog
Sprog: dansk 🗣️
engelsk 🗣️

Ordregivende myndighed
Identitet
Nationalt registreringsnummer: Dk
Kontakt
Enhed: Louise Skott Kristensen
Internetadresse: www.natureenergy.dk 🌏
Enhed: Server: ftp.enviweb.dk (Can be opened in Internet Explorer or in a FTP programme) — User: Korskro_Udbud_M&E — Password: Kro2017M&E

Supplerende oplysninger
Gennemgå organ
Navn: Klagenævn for udbud
Postadresse: Kampmandsgade 1
Postby: Copenhagen V
Postnummer: 1780
Land: Danmark 🇩🇰
Telefon: +45 33307600 📞
Internetadresse: www.klfu.dk 🌏
Oplysninger om frister for klageprocedurer:
Precise information on deadline(s) for lodging appeals: The dates shown in Act No 492 of 12.5.2010 concerning the enforcement of procurement rules, etc.
Complaints about the provision of agreement must be submitted within 12 months after the originator has signed the Agreement from the day after the day on which the customer has notified the affected candidates and tenderers. While a complaint lodged with the Complaints Board for Public Procurement, the appellant shall in writing in form the customer that the complaint lodged with the Complaints Board for Public Procurement, and whether the complaint is lodged in the stand still period. In cases where the complaint is not filed during the stand still period the appellant shall also indicate whether an appeal is requested delaying effect.
Vis mere
Tjeneste, hvorfra der kan indhentes oplysninger om klageproceduren
Navn: Konkurrencestyrelsen, Center for offentlig konkurrence
Postadresse: Nyropsgade 30
Telefon: +45 72268000 📞
Internetadresse: www.ks.dk 🌏
Kilde: OJS 2017/S 132-271175 (2017-07-07)
Bekendtgørelse om indgåede kontrakter (2017-11-29)
Objekt
Bekendtgørelsens metadata
Dokumenttype: Bekendtgørelse om indgåede kontrakter

Procedure
Bud-type: Finder ikke anvendelse

Reference
Datoer
Afsendelsesdato: 2017-11-29 📅
Offentliggørelsesdato: 2017-12-01 📅
Identifikatorer
Bekendtgørelsesnummer: 2017/S 231-483049
Henviser til bekendtgørelse: 2017/S 132-271175
EUT-S-nummer: 231
Kilde: OJS 2017/S 231-483049 (2017-11-29)
Nye indkøb inden for beslægtede kategorier 🆕
Relaterede søgninger 🔍
Produkter/tjenester:
Bygge- og anlægsarbejder Hoved- eller fagentrepriser i forbindelse... Bygge- og anlægsarbejde i forbindelse med... Bygge- og anlægsarbejder i forbindelse... Bygge-anlægsarbejde: gasproduktionsanlæg